3c attach 2
Exhibit C Page 2 WHEREAS, the Port supported the City's application for a Fostering Advancements In Shipping And Transportation For The Long-Term Achievement Of National Efciencies (FASTLANE) grant and for which a $45,000,000 award is currently proposed, $8,000,000 Freight Mobility Strategic Investment Board (FMSIB) grant, and various grants from the Puget Sound Regional Council; NOW, THEREFORE, the Parties agree as follows: 1. SCOPE OF WORK 1.1. Project Title: The S Lander St Grade Separation Project (CIP Project TC366150). 1.2. Description: The Project will construct a bridge on S Lander St between 1St Ave S and 4th Ave S spanning the BNSF mainline railroad tracks, including a separated multi-use path (or equivalent separated facility), and four, 11-feet travel lanes for vehicles. Intersections at 1St and 4th Avenues provide for separated left-turning movements with sufcient capacity for trucks to clear the intersection. The grade will not exceed 7.5% and signalization will be implemented such that trucks are not predicted to need to stop on the uphill grade based on the 2016 Transportation Discipline Report (DRAFT dated June 30, 2016). The construction phase cost of the Project is currently estimated to be One Hundred and Twenty-Five Million Dollars ($125,000,000) by the City. 1.3. Schedule: The Project is anticipated to begin construction in 2018 and open to trafc in late 2019, with Final Acceptance expected in 2020. 2. TERMS AND CONDITIONS 2.1. Implementing Agency: As the implementing agency the City shall ensure Project compliance with the State Environmental Policy Act (SEPA) and the National Environmental Policy Act (NEPA), and shall be responsible for obtaining all necessary permits and/or agreements. The City shall be responsible for accomplishing all aspects of the Project scope. 2.2. Contact Persons: The Parties to this Agreement shall designate person(s) to act as liaison for the Project. The contact persons shall meet on a mutually agreed upon, scheduled basis at a frequency appropriate to the phase and status of the Project. 2.3. Scope: The Project's dened scope as it relates to freight benets shall be based on input from the funding partners. Any changes during design or construction to the functionality of the Project and benets to the Port, as described in Section 1.2, and further illustrated by the description of Project benets, and the Project plan as provided in Exhibits B and C, shall require the Port's review to maintain the Port's funding obligation. (See Exhibit B and Exhibit C) The Port's funding is contingent upon the commitments outlined in Section 1.2. 2.4. System Mobility: The City recognizes that other east-west corridors in the Duwamish provide signicant utility to the Port. The City shall not reduce capacity on other east-west corridors in the Duwamish when the Project is completed without providing notice to and opportunity for input from the Port. Specically, S Holgate St provides connections from 1St Ave S to 6 Ave S over the mainline railroad crossing with 4 lanes of capacity, as well as connections from there to Airport Way and on an elevated bridge to Beacon Hill. The improvements at S Lander St should add to the mobility in the neighborhood, and are not intended to be offset by other lane reductions. The City will work with the Port and others to maintain efcient freight mobility throughout the Duwamish Manufacturing/Industrial Center (MIC). Should there be a specic proposal to close S Holgate St, or if safety issues arise on S Holgate St or other critical freight routes, or should the City be required by outside entities to perform mandated actions that require changes, the City will include the Port in discussions regarding the resolution of the issue, and specifically discuss how mobility is maintained. Page 3 2.5. Industrial Lands Protection: The City will support efforts to protect, preserve, and enhance issues. industrial lands and highlight the critical connection to freight mobility and other maritime 2.6. that includes a copy of the Progress Report: The City shall provide the Port with a report WSDOT/FHWA approved Project schedule (or analogous format), and nal engineer's estimate with contract bid items or summary of values. At the time of making application for each Port a progress report. The progress payment under Section 3, the City shall provide to the since the last report, an updated report will include a narrative describing the Project progress and percent completion of the major Project construction schedule showing the current progress that percent work elements, and a tabulation of the construction progress payments made such completion can be determined. issuance of Notices of 2.7. Inspections: The City shall provide opportunities for Project inspection by Final Inspection and/or Interim Final Inspections by Project Phase to the Port and other funding within the specied timeframe to partners. The Port shall participate in inspections of the Project inform punch-list requirements for Project Completion and to conrm its satisfaction that Project Prior to improvements, as dened in Section 1.2 and 2.3, are in place and fully operational. the Port the issuance of Notice of Physical Completion (to the Contractor), the City will provide Opportunity for verication of Final Inspection work. Project conditions existing at the time of the for nal payment is Project's Final Inspection, but not identied by the Port until the request made under 3.6, shall not be grounds for payment to be withheld. and/or 2.8. Public Involvement: The City shall be responsible for the continued public involvement Public Involvement Plan community outreach process for the Project. The City shall develop a it desire for the Project with input from the Port and shall be specic with requests should engagement from the Port. 3. COST REIMBURSEMENT AND FUNDING contribute an amount of The Port Commission authorizes the execution of the Agreement and agrees to Five-Million Dollars ($5,000,000) for the Project subject to the following conditions: and 3.1. All environmental review and permitting will be completed in accordance with Federal, State, local requirements; and 3.2. The Port and City continue to work together to ensure that the Project development both Parties implementation during design and construction meet the needs of ; Section 2.3; 3.3. The Project is constructed as described in Section 1.2 or modied consistent with a cash 3.4. The Port's total contribution shall not exceed Five Million Dollars ($5,000,000) as 3.7. payment, but pay be reduced as provided in Sections 3.5 and Dollars 3.5. Total construction cost is currently estimated to be One-Hundred Twenty-Five Million ($125,000,000). (See Exhibit D, Summary Estimates of Cost and Funding Shares, attached.) The Port shall make three payments as follows: a. The rst payment of Two Million ($2,000,000) shall occur after the City has made least 50% of the construction Contract progress payments to the Contractor totaling at value. (This is expected in 2018). b. The second payment of Two Million Dollars ($2,000,000) shall occur upon Substantial as issued by the City Completion (as defined in the construction contract) of the Project, to the Contractor. c. The nal payment of One Million Dollars ($1,000,000) shall occur upon Final Acceptance of Section 2.7 and (as dened in the construction contract), subject to the requirements Section 3.6, and the Port's receipt of a progress report and a letter from the City Project Manager attaching the Certicate of Final Acceptance. This is expected in 2020. The nal payment may be subject to a reduction based on Section 3.7 of this Agreement. Page 4 3.6. Prior to application for the nal payment, the City shall provide opportunity for the Port to inspect and verify that the requirements of Physical Completion have been met in accordance with Section 2.7. The City shall issue a letter to the Port requesting final payment upon Final Acceptance. 3.7. in the event the total construction contract value at the time of the Project's Final Acceptance ("Final Cost") is less than the Project estimate at the time of bid ("Bid Estimate"), the Port's total funding contribution shall be adjusted by a percentage that represents the proportional share of $5,000,000 to the Bid Estimate. 4. AMENDMENT Either Party may request changes to the provisions contained in this Agreement. Any change to this Agreement must be mutually agreed to by both Parties, in writing and executed with the same formalities as the original Agreement. 5. NOTIFICATION Any notice required or permitted to be given pursuant to this Agreement shall be in writing, and shall be sent postage prepaid by US. Mail, return receipt requested, to the following addresses unless othenivise indicated by the Parties to this Agreement: To the City: Jessica Murphy, Project Manager 700 Fifth Ave, Suite 3700 PO Box 4996 Seattle, WA 98124-4996 To the Port: Geraldine Poor, Regional Transportation Manager Port of Seattle 2711 Alaskan Way Seattle, WA 98121 6. RECORDS RETENTION AND AUDIT During the progress of the work on the Project and for a period not less than three (3) years from the date of nal payment by the Port to the City, the records and accounts pertaining to the Project and accounting thereof are to be kept available for inspection and audit by the Port and the City shall provide the Port with copies of all records, accounts, documents, or other data pertaining to the Project upon the Port's request. If any litigation, claim, or audit is commenced, the records and accounts along with supporting documentation shall be retained until all litigation, claims, or audit ndings have been resolved, even though such litigation, claim, or audit continues past the typical three year retention period. This provision is not intended to alter or amend records retention requirements established by applicable state and federal laws. 7. DISPUTES The designated representatives under section 5.0, NOTIFICATION, shall use their best efforts to resolve disputes between the Parties. If the designated representatives are unable to resolve a dispute, then the responsible Project directors for each Party shall review the matter and attempt to resolve it. If the Project directors are unable to resolve the dispute, the matter shall be reviewed by the department director or chief executive ofcer of each Party or his or her designee. The Parties agree to exhaust each of these procedural steps before seeking to resolve disputes in a court of law or any other forum. Page 5 8. EFFECTIVENESS AND DURATION will remain in effect until This Agreement is effective upon the last date of execution by both Parties and amended or terminated. Project completion, unless othenNise stated herein or unless 9. TERMINATION notice to the other Either Party may terminate this Agreement at any time upon thirty (30) days written sooner than sixty (60) days from the execution Party, but said written notice of termination shall not occur of this Agreement. If either Party decides to terminate this Agreement, the Port shall reimburse the City of notice of termination, its proportionate share of all costs payable under this Agreement at the time to the notice of termination, but . including those obligations that the City has contractually undertaken prior of the Port's Five in no case shall the Port be obligated to reimburse the City any amounts in excess Million Dollars ($5,000,000) contribution set forth in Section 3 of this Agreement. 10. INDEMNIFICATION AND HOLD HARMLESS and hold 10.1 To the maximum extent permitted by law, each party shall protect, defend, indemnify, harmless the other party, its ofcers, employees, and agents from any and all costs, claims, from the negligent judgments, and/or awards of damages, arising out of or in any way resulting Each party acts or omissions of said indemnifying party, its ofcers, employees, and/or agents. extend to any claim, demand, and/or cause of agrees that its obligations under this subsection mutual action brought by or on behalf of any of its employees or agents. Each party, by that would otherwise negotiation, hereby waives, as respects the other party only, any immunity be available to it against such claims under the Industrial Insurance provisions of Title 51 RCW. In the event the indemnied party incurs any judgment, award, and/or cost arising therefrom, awards and costs shall including attorney's fees to enforce this provision, all such judgments, be recoverable from the indemnifying party. 10.1 of this 10.2 The indemnication, hold harmless, and/or waiver obligation described in Section Agreement shall survive the termination of this Agreement. 11. VENUE and the legal This Agreement shall be deemed to be made in the County of King, State of Washington, in ascordance with the laws of the State of rights and obligations of the City and Port shall be determined of King, Washington. All legal actions in connection with this Agreement shall be brought in the County State of Washington. 12. OTHER PROVISIONS of 12.1 Severability. A determination by a court of competent jurisdiction that any provision or invalidate the remainder this Agreement or any part thereof is illegal or unenforceable shall not cancel of such provision of this Agreement, which shall remain in full force and effect. are not a 12.2 Interpretation. The captions of the Sections or Paragraphs of this Agreement the context of this Agreement, part of the terms or provisions of this Agreement. Whenever required by feminine and the singular shall include the plural and the plural shall include the singular. The masculine, neuter genders shall each include the other. 12.3 Construction Contract Terms. The terms Final Inspection, Interim Final Inspections, Final Acceptance shall Project Phase, Project Completion, Physical Completion, Substantial Completion, Page 6 have the meaning set forth in the City's standard specications found at httg://www.seattle.gov/utillEngineerinngtandardSpecsPlans/indexhtm 12.3 Waivers. All waivers shall be in writing and signed by the waiving Party. Either Party's failure to enforce any provision of this Agreement shall not be a waiver and shall not prevent either Party from enforcing that provision or any other provision of this Agreement in the future. 12.4 Force Majeure. If either Party cannot perform any of its obligations due to events beyond its reasonable control (other than the payment of money), the time provided for performing such obligations shall be extended by a period of time equal to the duration of such events. Events beyond a Party's reasonable control include, but are not limited to, acts of God, war, civil commotion, labor disputes, strikes, re, ood or other casualty, shortages of labor or materials, government regulations or restrictions and weather conditions. 12.5 Joint Drafting Effort. This Contract shall be considered for all purposes as prepared by the joint efforts of the Parties and shall not be construed against one Party or the other as a result of the preparation, substitution, submission or other event of negotiation, drafting or execution hereof. 12.6 Third Party Beneficiaries. Nothing in this Agreement is intended to, nor shall be construed to give any rights or benets in the Agreement to anyone other than the Port and the City, and all duties and responsibilities undertaken pursuant to this Agreement will be for the sole and exclusive benet of the Port and the City and not for the benet of any other party. 12.7 Authority. Each individual executing this Agreement on behalf of the Port or the City represents and warrants that he or she is duly authorized to execute and deliver the Agreement on behalf of the Port or the City. 12.8 Exhibits. This Agreement includes the following exhibits: Exhibit A: Lander Vicinity Map; Exhibit B: Project Benefits; Exhibit C: Project Plan & Prole and Cross Sections; and Exhibit D: Summary Estimate of Cost and Funding Shares which shall be deemed incorporated into this Agreement by this reference. IN WITNESS WHEREOF, the Parties hereto have executed this Agreement which shall be effective upon the last date set forth below. PORT OF SEATTLE CITY OF SEATTLE Theodore J. Fick, Date: I 20' Item No.: 6a_attach 1 Meeting Date: August 9, 2016 Exhibit A - Vicinity Map (Local) Project Area Page 2 of 2 = Freight Rail Passenger Rail Light Rail :7 Yesler Way 18> Bus Routes S Main Bike Routes S Jackson Transportation Hub 9 Starbucks HQ S Dearborn St o T Seattle Public Terminal _ ' Schools HQ ?..... 9 Sports and -~' Event Venues ," o r S Ave 1st I Maintenance Facility Way S ~ I S j Way MOVING PEOPLE _ Ave 0 Two major employers, more I than 600 businesses, and Marginal . 4th Airport 350 property owners are E adjacent to the project in the SODO District 0 Two stadiums and one event center attract millions of visitors to the area each year 0 Over 10000 cars use the S Lander St crossing daily 0 1.000 hours of vehicle delay each day at the S Lander St crossing Ter t" J \SWSppkane . /F.. 115'(0'2.5::m \~___A t S LANDER ST GRADE SEPARATION AND RAILROAD SAFETY PROJECT FACT SHEET Spring 2016 A grade separated crossing on S Lander St will improve mobility, safety and access for people and freight S Lander St is a vital route for freight and King St Project Area Station 5 general travel in the largest manufacturing Port of Seattle Terminal S. Dearborn St industrial center in the Pacific Northwest. It Terminal & Rail 46 99 90 Yard Gates provides direct connections to Port of Seattle 90 Transit and 519 facilities and freight operational support Passenger centers, which contribute to 75,000 existing jobs Rail Hub Amtrak and an additional 25,000 jobs that are forecasted Rail Maintenance Facility by 2040. Terminal S. Ho S. Ho lga lga te St te St 30 S evA ts1 S evA ts1 S evA ht4 The Problem: Every day, roughly 100 train crossings occur on S Lander St and surrounding BNSF Yard streets. As a result, the street is closed for an average of 4.5 hours per day, impacting the Terminal 18Terminal 18 S Lander St S Lander St S evA ht6 mobility of tens of thousands of people and severely affecting freight access to port and manufacturing facilities critical to the local and Terminal HARBOR S. 25 S. Hanford St Hanford St national economy. As the region continues its Terminal ISLAND S. Hor S. Hor ton St ton St 5 rapid growth and rail operations in the area expand in the coming years, the S Lander St SW Spokane St lanigraM E S yaW tropriA "bottleneck" will further put at risk the Pacific lanigraM W Northwest's economic vitality. The Solution: The S Lander St project will yaW construct a grade separated crossing over 5 yaW (UP) ARGO BNSF's tracks on S Lander St between 1st and 99 Intermodal 4th avenues. This crossing will provide a Yard roadway unimpeded by rail operations. PROJECT BENEFITS Reliable Movement of Goods and Improved Safety and Access for All Users Services Critical to Region's Economy Creates dependable access to Increases safety by separating trains from people one of the largest port operations driving, walking and riding bikes. Today nearly 500 in the United States track violations occur each day Improves freight train Ensures reliable access for public safety and movements for more than 3,000 emergency responders rail cars each day Improves reliability for travel to Interstates 5 and 90 Reduces truck delays, congestion, and other key national freight corridors and emissions for more than Provides access between regional transit hubs and 13,000 vehicles each day employment centers Exhibit C - Plan and Profile Page 1 of 3 P H P OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP H OHP OHP OHP OHP P OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP O OHP OHP OH OHP OHP OHP OHP OHP O O LOOKING NORTH * - * Exhibit C - Plan and Profile Page 2 of 3 OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP H P OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP O OHP OHP OHP OHP OHP HP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP OHP 1st Ave S OHP OHP OHP OHP OHP OHP Occidental Ave S OHP OHP 3rd Ave S 4th Ave S LOOKING NORTH LEGEND: GRADING LIMITS IF NO FUTURE TRACK WEST SIDE GRADING LIMITS IF FUTURE TRACK REQUIRED @ 22.5' CLEARANCE GRADING LIMITS IF FUTURE TRACK REQUIRED @ 23.5' CLEARANCE Exhibit C - Cross Section Page 3 of 3 S Lander St Cross Section Looking West - -_- :1 EB LANE EB LANE WB LANE WB LANE LANE MULTl-USE SEPARATOR FACILITY EXHIBIT D Summary Estimates of COST and FUNDING SHARES ESTIMATE OF CONSTRUCTION COST: $125 million SUMMARY ESTIMATE OF CONSTRUCTION FUNDING SHARES: Federal USDOT (FASTLANE) 45,000,000 State - Freight Mobility Strategic Investment Board (FMSIB) 8,000,000 State Connecting Washington 1,500,000 Local Levy to Move Seattle 20,000,000 Local - Port of Seattle 5,000,000 Local BNSF (pursuant to 23 CRF 666.210) 5,000,000 Local Other Funding Sources (TBD) 40,500,000 Total: $125,000,000
Limitations of Translatable Documents
PDF files are created with text and images are placed at an exact position on a page of a fixed size.
Web pages are fluid in nature, and the exact positioning of PDF text creates presentation problems.
PDFs that are full page graphics, or scanned pages are generally unable to be made accessible, In these cases, viewing whatever plain text could be extracted is the only alternative.